The Building Contractor Contract is a crucial legal document used in the Indonesian construction industry to formalize the relationship between project owners and contractors undertaking construction works. This document type is essential for compliance with Indonesian construction law, particularly Law No. 2 of 2017 on Construction Services and related regulations. It is typically used for both commercial and residential construction projects, incorporating mandatory local content requirements, environmental standards, and safety regulations specific to Indonesia. The contract provides comprehensive coverage of project specifications, timeline, payment terms, quality standards, and dispute resolution mechanisms, while ensuring alignment with Indonesian civil law principles and construction industry practices. This Building Contractor Contract is particularly important as it incorporates specific Indonesian regulatory requirements that may differ from international construction contract standards, making it essential for both domestic and international contractors operating in Indonesia.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train 蜜桃传媒's AI
You keep IP ownership聽of your docs
Alternatively...
1. Parties: Identification of the employer/owner and the contractor, including their complete legal names, registration numbers, and addresses
2. Background: Context of the construction project, including brief description of the project and the parties' intentions
3. Definitions and Interpretation: Detailed definitions of terms used throughout the contract and rules for contract interpretation
4. Scope of Works: Detailed description of the construction works to be performed by the contractor
5. Contract Price and Payment Terms: Amount payable, payment schedule, payment conditions, and invoicing requirements
6. Project Timeline: Commencement date, completion date, milestones, and provisions for extensions of time
7. Contractor's Obligations: Key responsibilities including workmanship, materials, compliance with laws, and safety requirements
8. Employer's Obligations: Key responsibilities including site access, permits, approvals, and provision of necessary information
9. Quality and Standards: Required quality standards, inspections, testing procedures, and acceptance criteria
10. Variations: Process for requesting, approving, and implementing changes to the scope of works
11. Health and Safety: Safety requirements, compliance with regulations, and accident prevention measures
12. Insurance and Indemnities: Required insurance coverage and indemnification obligations of both parties
13. Performance Security: Requirements for performance bonds or bank guarantees
14. Defects Liability: Defects notification period, remediation process, and warranties
15. Force Majeure: Definition of force majeure events and their consequences
16. Termination: Grounds for termination, termination process, and consequences
17. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
18. Governing Law: Specification of Indonesian law as governing law and jurisdiction
19. General Provisions: Standard clauses including notices, assignment, and entire agreement
1. Environmental Management: Required for projects with significant environmental impact, detailing environmental protection measures and compliance requirements
2. Local Content Requirements: Required for projects subject to Indonesian local content regulations, specifying minimum local content percentages
3. Intellectual Property Rights: Required when the project involves design elements or proprietary technology
4. Site Conditions: Required for projects where ground conditions or existing structures may impact construction
5. Temporary Works: Required when significant temporary structures or facilities are needed
6. Liquidated Damages: Optional section specifying pre-agreed damages for delay or performance failures
7. Advance Payment: Required when advance payments are part of the payment structure
8. Subcontracting: Required when subcontracting will be permitted, specifying conditions and approval requirements
1. Schedule 1 - Scope of Works: Detailed technical specifications, drawings, and work descriptions
2. Schedule 2 - Project Timeline: Detailed construction schedule, milestones, and critical path activities
3. Schedule 3 - Bill of Quantities: Itemized list of works with quantities and rates
4. Schedule 4 - Payment Schedule: Detailed payment terms, milestones, and payment procedures
5. Schedule 5 - Site Information: Site plans, access points, and existing conditions
6. Schedule 6 - Quality Assurance Plan: Detailed quality control procedures and standards
7. Schedule 7 - Forms and Certificates: Template forms for variations, completion certificates, and other project documents
8. Schedule 8 - Insurance Requirements: Detailed insurance specifications and minimum coverage requirements
9. Schedule 9 - Key Personnel: List of key personnel from both parties with roles and responsibilities
10. Appendix A - Permits and Licenses: Copies of relevant permits, licenses, and approvals
11. Appendix B - Safety Management Plan: Detailed health and safety procedures and requirements
Authors
Find the document you need
Simple Building Contract
A simplified building contract compliant with Indonesian construction laws, suitable for straightforward construction projects in Indonesia.
Download
Building Contractor Contract
An Indonesian law-governed agreement between a project owner and building contractor establishing terms and conditions for construction works.
Download
Home Construction Contract
An Indonesian law-governed contract establishing terms and conditions between a homeowner and contractor for residential construction projects.
Download
Standard Building Contract
An Indonesian law-governed construction agreement setting out terms and conditions for building projects, compliant with local construction regulations.
Download
General Contractor Subcontractor Agreement
An Indonesian law-governed agreement between a general contractor and subcontractor defining construction service delivery terms and obligations.
Download
Home Builder Contract
An Indonesian law-governed contract between a builder and homeowner for residential property construction, complying with local construction and consumer protection regulations.
Download
Construction Subcontract
An Indonesian law-governed agreement between main contractor and subcontractor for delegating specific construction works, compliant with Indonesian Construction Services Law.
Download
General Contractor Agreement
An Indonesian law-governed agreement between a project owner and general contractor establishing terms for construction services.
Download
骋别苍颈别鈥檚 Security Promise
蜜桃传媒 is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your data is private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on 蜜桃传媒 is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
